Managing Delays From the Construction Side

Not all construction delays are the fault of the construction contractor. By keeping the lines of communications open, the client and contractor together can work to avoid any serious slowdowns in the project.

Project managers should be aware of early warning of delays caused by the client, main contractor or your own people. Client delays arise because they may change their minds, give instructions too late or are slow in approving drawings and plans. They tend to overlook the fact that these delays push back the start for contractors or sub-contractors, and that the contractor is powerless to avoid these delays.

Main contractor delays usually involve construction work being completed late, causing subsequent stages to fall behind schedule. In some cases, delays are the result of mismanagement and a lack of coordination.

Last but not least, the subcontractors themselves may cause delays; for example, by under-resourcing the project in the early stages or by not completing design drawings and getting them approved on time.

Make sure delays outside your control are recognized and documented. Such delays can impact you financially and need to be recorded and the financial impact dealt with by the responsible party. You should not have to bear the cost of other peoples’ delays, nor should you be blamed for them.

This article originally appeared in the issue of .

Featured

  • Spaces4Learning Trends & Predictions for Educational Facilities in 2026: Part II

    As education leaders look toward 2026, the design of K–12 and higher education facilities is being reshaped by powerful, converging forces. Survey respondents point to the rapid growth of Career and Technical Education, deeper alignment with workforce and industry needs, and the accelerating influence of AI and emerging technologies.

  • Little Grand Market

    Designing for Belonging: Why Student Wellness Starts with Space

    From walkable site planning to flexible interiors, intentional design choices play a critical role in how students experience comfort, connection, and community.

  • UNT Dallas Holds Ribbon-Cutting Ceremony for $100M STEM Building

    The University of North Texas at Dallas in Dallas, Texas, recently celebrated the opening of its new, $100-million STEM Building, according to local news. The ceremony on Dec. 2 preceded the first day of classes in the facility on Jan. 12, 2026.

  • University of Arizona Approves New Residence Hall

    The Arizona Board of Regents recently approved plans for a new residence hall at the University of Arizona in Tucson, Ariz., according to a news release. The new facility is scheduled to open in fall 2028 and have the capacity for more than 1,200 students, enforcing a new university expectation that all first-year students live on campus.